Scaffolding Contract Agreement Hire Sample

We will adequately protect ourselves against any liability on our part to our own craftsmen and third parties for the assembly and dismantling of scaffolding on site. 5.3 All modification work carried out by the Company at the request of the Tenant, unless calculated individually prior to the work and subject to contractual agreement, will be calculated in accordance with the Company`s standard tariff plan. If a copy of it is not provided with this offer, the tenant must request a copy from the company. 3.5 It is the Tenant`s responsibility to notify the Company when the scaffolding structure(s), cradles or other materials constituting one or more scaffolding structures are ready to be dismantled. 7.1.3 The total liability of the Company or the subcontractor appointed by it in respect of the contract, tort (including negligence or breach of statutory duty), misrepresentation or otherwise arising out of the performance or intended performance of this Agreement shall be limited to the price of the contract; and the Company shall not be liable to the Renter for indirect or consequential damages, however caused, including contractual delays. (whether loss or profit, loss of business, exhaustion of goodwill or otherwise), due to or due to any cause beyond its control and arising out of or in connection with the Contract. 2.4 An order from the Renter to the Company shall be deemed to constitute an offer by the Tenant to lease the facility under these Terms. No terms other than those expressly set forth herein shall be implied or deemed to form part of any contract between us and the Customer. During the term of a contract entered into according to our estimates, the wages and conditions of employment of our local workers and those of the client must be determined from time to time by the National Joint Council of the Construction Industry, and the client must indemnify us against any loss or damage that we may have on the construction site or elsewhere in connection with any failure of the client to pay or maintain these wages. or conditions. 4.4 The Company or its designated subcontractor is not responsible for roofing materials (including frames, slate, tiles, gutters, downspouts or related materials or fasteners), features related to roofs, lighting, antennas, chimneys, walkways or other structures associated with roofs or other damage, but caused during construction, dismantling or modification.

The rental period begins 8 weeks after the customer has opened the scaffolding. If we accept the relocation of part of a scaffolding at the end of the period specified in our estimate, prorated rent is payable for that continuation. 4.2 The Renter is responsible and shall indemnify the Company, its designated subcontractor (and/or any other person involved) for any damage caused by the Renter, its employees or the User of the Structure interfering with the initial position of the Structure(s) or Facility determined by the Company or its designated subcontractor. 1.1 In these Terms, the following words have the following meanings: the Tenant: the person(s), company(ies), company or public entity renting the Work to the Company; The Company: Any member of Admiral Scaffolding Group Ltd.; the contract: a lease agreement for the facility for the rental period specified in this offer, which contains the conditions contained herein; the designated subcontractor: an undertaking to which the contract for the supply of the works for the execution of the works is awarded. Place of delivery: any place agreed between the Company and the Tenant where the delivery of the equipment must take place on condition 3; the factory: scaffolding materials delivered to the point of delivery and assembled by the Company; the rental period: the rental period that begins at the time of delivery by the company and ends on the day the tenant has fulfilled his obligations. During the rental period, the customer must compensate us for all damage caused to our equipment, for any reason whatsoever, reasonable wear and tear is to be expected, and except in the cases provided herein, he must also make any claim to us for any source of injury to persons or property caused by or in connection with or use of the scaffolding, completely and completely free. Compliance with all costs and fees related to the fact that they result from customary law or law. 6.8 In the event of non-payment by the Tenant, the Company reserves the right to withhold resources after 7 days of notification to the Tenant until the situation is resolved. 6.9 If the Renter defaults on payment by the Company, all debts owed by the Company to the Renter will become due in full. All contracts for the delivery, assembly, rental and dismantling of scaffolding are only valid and binding if they are concluded in writing and are subject to the special and general conditions set out in this document. 3.2 The Company and its designated subcontractor shall exercise due diligence and care to ensure that the facility is appropriate, sufficient and appropriate for the purposes of the Contract and that, when the facility is fully constructed; The structure(s) must comply from time to time with applicable legislation and codes of conduct that affect scaffolding and related building codes. 9.1 Subject to clause 9.2 below, if performance of the Contract is delayed beyond the Reasonable Control of the Company, including, but not limited to, force majeure, government acts, loss or damage caused by fire, civil injury, disobedience, civil action (regardless of cause), lockouts.

Strikes or other labour disputes or restrictions or delays on the part of other contractors or other persons, regardless of how busy they may be, or inability or delay in securing such employees or materials necessary for the proper performance of the contract, then, when such an event is described, the Company must inform the tenant in writing and of an extension of the period of performance of the contract, to the extent that they affect the framework, are agreed between the parties. The terms of any contract between us, the Client, shall be construed in accordance with the laws of England and any dispute arising between us and the Client shall be arbitrated under the Arbitration Act 1950 or any amendment thereto, provided that nothing in this condition precludes a claim for equitable relief in the High Court of Justice of a district court. 3.1 The Company and its designated subcontractor are responsible for the delivery of the Equipment to the place of delivery, the construction of the scaffolding structures (“Structures”), dismantling and removal. 3.7 The Lessee grants the Company or its designated subcontractor, its agents and employees an irrevocable license at any reasonable time to enter any premises where the facility is or may be stored in order to inspect the facility or, if the contract has been terminated, to recover the facility. The customer must ensure that the floor and/or basement of our scaffolding is sufficient to accommodate the loads to be applied and provide the necessary spreaders. We reserve the right to change the price of a contract to take into account fluctuations in salary increases or fluctuations in our costs for and in connection with the employment of staff and labour staff. The start of construction at the time requested by the customer requires that we have adequate materials and labor when we are asked to: to start working, and that we will inform you appropriately. .